The following Construction practice note provides comprehensive and up to date legal information covering:
This Practice Note considers the Contractor’s obligations in relation to time under the JCT 2011 and 2016 contracts. It looks at commencement of work, the obligation to proceed regularly and diligently, the Contractor’s programme, events entitling the Contractor to an extension of time (known as Relevant Events), acceleration, and the obligation to complete by the Completion Date (including liability for liquidated damages for delay). It refers to clauses in the 2011 and 2016 editions of the JCT Standard Building Contract (SBC) With Quantities, but comparable provisions are found within the other JCT contracts.
The Contractor’s key obligations in relation to time (as set out in clause 2.4) are to:
proceed regularly and diligently with the Works
complete the Works (ie achieve practical completion) by the ‘Completion Date’
However, and as considered below, the ‘Completion Date’ can change during the course of the project:
if the Contractor is granted an extension of time
in the case of a Variation or acceleration, as a result of a ‘Pre-agreed Adjustment’
It is also possible for the contract to provide for sectional completion, in which case the Contractor must complete each Section by the Completion Date for that Section. For more on sectional completion generally, see Practice Note: Sectional completion.
Once the Contractor has been given possession of the site, it is required to begin construction of the Works (clause 2.4). Possession
Free trials are only available to individuals based in the UK
Complete all the fields above to proceed to the next step.
**Trials are provided to all LexisPSL and LexisLibrary content, excluding Practice Compliance, Practice Management and Risk and Compliance, subscription packages are tailored to your specific needs. To discuss trialling these LexisPSL services please email customer service via our online form. Free trials are only available to individuals based in the UK. We may terminate this trial at any time or decide not to give a trial, for any reason. Trial includes one question to LexisAsk during the length of the trial.
To view the latest version of this document and thousands of others like it, sign-in to LexisPSL or register for a free trial.
Existing user? Sign-in
Take a free trial
Take a free trial
The third edition of the Standard Commercial Property Conditions was published on 27 April 2017 a
AML and counter-terrorist financing—source of funds and source of wealthSource of funds and wealth was a key focus of the SRA’s Preventing Money Laundering and Financing of Terrorism thematic review, published in March 2018. Its findings included that:•most firms understood the distinction between
Arms length management organisations (ALMOs)An arms length management organisation (ALMO) is a not-for-profit company that provides housing services on behalf of a local housing authority (LHA). Usually an ALMO is set up by the LHA to manage and improve all or part of its housing stock with the LHA
Guide to using the Lexis®PSL Employment Schedule of Loss applicationThe automated unfair dismissal schedule of loss is designed to make the preparation of a schedule more efficient, accurate and also easier to update. It:•can be used to create a schedule for a claimant or a counter-schedule for a
0330 161 1234