The Contract comprises the completed Standard Building Contract With Quantities 2024 published by the JCT subject to the following amendments: RECITALS Fifth Recital Fifth Recital Delete the Fifth Recital and substitute:‘The Contractor has supplied the Architect/Contract Administrator with a master programme and a Schedule of Information Requirements.’ Twelfth Recital Twelfth Recital Delete the first sentence and replace with: 'The Contractor has inspected the Site and satisfied itself as to its dimensions, location and other relevant matters, and where there is a Contractor’s Design Portion, has examined the Employer’s Requirements and is satisfied that the Contractor’s Proposals will meet the Employer’s Requirements, and has agreed to accept responsibility for the entire design contained in the Employer’s Requirements and the Contractor’s Proposals.' ARTICLES Articles 6 and 7 [See drafting note] Article 9 Article 9 Arbitration Delete Article 9 and insert ‘Not used.’ Article 11 Insert new Article 11 as follows: ‘Article 11 [To be added on the face of the contract] The Employer and the Contractor agree that the modifications in the Schedule of Amendments attached hereto (as initialled by the parties) shall be incorporated into this

ARCHIVED: This Precedent has been archived and is not maintained. The Contract comprises the completed Standard Building Contract Without Quantities 2011 published by the JCT (as modified by Amendment 1: CDM Regulations 2015) as further amended below: RECITALS Fifth Recital Fifth Recital Delete the Fifth Recital and substitute:'The Contractor has supplied the Architect/Contract Administrator with a master programme and a Schedule of Information Requirements.' Twelfth Recital Twelfth Recital Delete the first sentence and replace with:'The Contractor has inspected the Site and satisfied himself as to its dimensions, location and other relevant matters, and where there is a Contractor’s Design Portion, has examined the Employer’s Requirements and is satisfied that the Contractor’s Proposals will meet the Employer’s Requirements, and has agreed to accept responsibility for the entire design contained in the Employer’s Requirements and the Contractor’s Proposals.' ARTICLES Article 6 Article 6 At the end of Article 6 insert:'The Contract Sum includes the Contractor’s price for fulfilling the duties of Principal Contractor.' Article 8 Article 8 Arbitration Delete Article 8 and insert 'All references to arbitration in this Contract are deleted.' Article

The Contract comprises the completed Standard Building Contract Without Quantities 2016 published by the JCT subject to the following amendments: RECITALS Fifth Recital Fifth Recital Delete the Fifth Recital and substitute: ‘The Contractor has supplied the Architect/Contract Administrator with a master programme and a Schedule of Information Requirements.’ Twelfth Recital Twelfth Recital Delete the first sentence and replace with:'The Contractor has inspected the Site and satisfied himself as to its dimensions, location and other relevant matters, and where there is a Contractor’s Design Portion, has examined the Employer’s Requirements and is satisfied that the Contractor’s Proposals will meet the Employer’s Requirements, and has agreed to accept responsibility for the entire design contained in the Employer’s Requirements and the Contractor’s Proposals.' ARTICLES Article 5 Article 5 In the first line after ‘for the purposes of the CDM Regulations’, insert ‘and the Dutyholder Regulations’ Article 6 Article 6 In the first line, after ‘for the purposes of the CDM Regulations’, insert ‘and the Dutyholder Regulations’At the end of Article 6 insert: 'The Contract Sum includes the Contractor’s price for fulfilling

The Contract comprises the completed Standard Building Contract Without Quantities 2024 published by the JCT subject to the following amendments: RECITALS Fifth Recital Fifth Recital Delete the Fifth Recital and substitute: ‘The Contractor has supplied the Architect/Contract Administrator with a master programme and a Schedule of Information Requirements.’ Twelfth Recital Twelfth Recital Delete the first sentence and replace with:'The Contractor has inspected the Site and satisfied itself as to its dimensions, location and other relevant matters, and where there is a Contractor’s Design Portion (CDP), has examined the Employer’s Requirements and is satisfied that the Contractor’s Proposals will meet the Employer’s Requirements, and has agreed to accept responsibility for the entire design contained in the Employer’s Requirements and the Contractor’s Proposals.' ARTICLES Articles 6 and 7 [See drafting note] Article 9 Article 9 Arbitration Delete Article 9 and insert: ‘Not used.’ Article 11 Insert new Article 11 as follows: ‘Article 11 [To be added on the face of the contract] The Employer and the Contractor agree that the modifications in the Schedule of Amendments attached hereto (as initialled by the parties) shall be incorporated

This Contract comprises the completed RIBA Standard Professional Services Contract 2020 (2024 amendment) published by the Royal Institute of British Architects subject to the following amendments: CONTRACT DETAILS M. Supplementary Rights In each case after ‘on the terms attached hereto as Appendix’, delete ‘provided such terms are substantially no more onerous than the above’. CONTRACT CONDITIONS Definition of Terms Insert new definitions as follows: ‘Assignment of Receivables Regulations: the Business Contract Terms (Assignment of Receivables) Regulations 2018, SI 2018/1254.’ ‘Force Majeure: means any event or sequence of events beyond a party’s reasonable control[ and that could not have been reasonably anticipated or avoided] and which prevents it from, or delays it in, performing its obligations under this Contract including[, but not limited to,] (a) an act of God, fire, flood, drought, earthquake, windstorm or other natural disaster; (b) an act of any sovereign including war (or threat of, or preparation for war), armed conflict (or threat of, or preparation for, armed conflict), invasion, act of foreign enemies, hostilities (whether war be declared or not), rebellion,

The Contract comprises the completed Design and Build Contract for use in Scotland 2016 Edition published by the SBCC subject to the following amendments: RECITALS Third Recital Third Recital Delete and insert:‘The Contractor has:(a) inspected the Site and satisfied himself as to its dimensions, location and other relevant matters(b) examined the Employer’s Requirements and is satisfied that the Contractor’s Proposals and Contract Sum Analysis will meet the Employer’s Requirements, and(c) agreed to accept responsibility for the entire design contained in the Employer’s Requirements and the Contractor’s Proposals.’ ARTICLES Article 1 Article 1 After ‘shall’ insert ‘carry out and’ Article 6 Article 6 At the end of Article 6 insert:‘The Contract Sum includes the Contractor’s price for fulfilling the duties of Principal Contractor.’ Article 8 Article 8 Delete Article 8 and insert:‘Not used.’ Article 11 Insert new Article 11 as follows: ‘Article 11 [ To be added on the face of the contract ] The Employer and the Contractor agree that the modifications in the Schedule of Amendments attached hereto (as initialled by the parties) shall be incorporated into this Contract and the provisions

The Contract comprises the completed Standard Building Contract With Approximate Quantities for use in Scotland 2016 published by the SBCC subject to the following amendments: RECITALS Fifth Recital Fifth Recital Delete the Fifth Recital and substitute:‘The Contractor has supplied the Architect/Contract Administrator with a master programme and a Schedule of Information Requirements.’ Twelfth Recital Twelfth Recital Delete the first sentence and replace with:‘The Contractor has inspected the Site and satisfied himself as to its dimensions, location and other relevant matters, and where there is a Contractor’s Design Portion, has examined the Employer’s Requirements and is satisfied that the Contractor’s Proposals will meet the Employer’s Requirements, and has agreed to accept responsibility for the entire design contained in the Employer’s Requirements and the Contractor’s Proposals.’ ARTICLES Article 6 Article 6 At the end of Article 6 insert:‘The Tender Price includes the Contractor’s price for fulfilling the duties of Principal Contractor.’ Article 8 Article 8 Arbitration Delete Article 8 and insert ‘Not used.’ Article 11 Insert new Article 11 as follows: ‘Article 11 [To be added on the face of the contract]

The Contract comprises the completed Standard Building Contract With Quantities for use in Scotland 2016 published by the SBCC subject to the following amendments: RECITALS Fifth Recital Fifth Recital Delete the Fifth Recital and substitute:‘The Contractor has supplied the Architect/Contract Administrator with a master programme and a Schedule of Information Requirements.’ Twelfth Recital Twelfth Recital Delete the first sentence and replace with: 'The Contractor has inspected the Site and satisfied himself as to its dimensions, location and other relevant matters, and where there is a Contractor’s Design Portion, has examined the Employer’s Requirements and is satisfied that the Contractor’s Proposals will meet the Employer’s Requirements, and has agreed to accept responsibility for the entire design contained in the Employer’s Requirements and the Contractor’s Proposals.' ARTICLES Article 6 Article 6 At the end of Article 6 insert:'The Contract Sum includes the Contractor’s price for fulfilling the duties of Principal Contractor.' Article 8 Article 8 Arbitration Delete Article 8 and insert ‘Not used.’ Article 11 Insert new Article 11 as follows: ‘Article 11 [To be added on the face of the contract] The

The Contract comprises the completed Standard Building Contract Without Quantities for use in Scotland 2016 published by the SBCC subject to the following amendments: RECITALS Fifth Recital Fifth Recital Delete the Fifth Recital and substitute: ‘The Contractor has supplied the Architect/Contract Administrator with a master programme and a Schedule of Information Requirements.’ Twelfth Recital Twelfth Recital Delete the first sentence and replace with:'The Contractor has inspected the Site and satisfied himself as to its dimensions, location and other relevant matters, and where there is a Contractor’s Design Portion, has examined the Employer’s Requirements and is satisfied that the Contractor’s Proposals will meet the Employer’s Requirements, and has agreed to accept responsibility for the entire design contained in the Employer’s Requirements and the Contractor’s Proposals.' ARTICLES Article 6 Article 6 At the end of Article 6 insert: 'The Contract Sum includes the Contractor’s price for fulfilling the duties of Principal Contractor.' Article 8 Article 8 Arbitration Delete Article 8 and insert: ‘Not used.’ Article 11 Insert new Article 11 as follows: ‘Article 11 [To be added on the face of the contract] The

A schedule served by a landlord on its tenant, which sets out the items of disrepair at a property caused by the tenant’s failure to perform its repairing, decorating, and where appropriate, reinstatement obligations in the lease. The items of work detailed in the schedule may be costed.

The schedule of absences spreadsheets below may be used to calculate a person’s absences from the UK for the purposes of various application types. Schedule of absences for settlement in work routes, Long Residence and naturalisation applications (incorporating ‘rolling absences’ tool) Click on the below link to download the spreadsheet: This spreadsheet may be used in preparing an application for indefinite leave to remain in the UK in work, business and investment routes under the Immigration Rules. All routes which have been ‘simplified’ for the post-Brexit Immigration system refer to indefinite leave to remain as settlement. It may also be used for naturalisation as a British citizen under section 6 of British Nationality Act 1981 (although the rolling absences feature will not be relevant in this context). In work, business and investment routes it is suitable for persons who have relevant initial leave granted under the Immigration Rules in force on or after 11 January 2018, as they will be fully subject to the ‘rolling absences’ requirement in relation to indefinite leave to remain, and the spreadsheet incorporates

UPON THE APPLICATION OF THE [PARTY] [the parties and their representatives who attended] AND UPON HEARING AND UPON