The following Construction Q&A provides comprehensive and up to date legal information covering:
The standard form JCT 2011 contracts contain a number of events, called 'Relevant Events', that may entitle the contractor to an extension of time in which to complete the works (to avoid completing its works after the contractual completion date and becoming liable to pay the employer liquidated damages). See Practice Note: Extensions of time under construction contracts.
One of these Relevant Events is 'exceptionally adverse weather conditions', see for example clause 2.29.9 in the JCT Standard Building Contract With Quantities 2011 or clause 2.26.8 in the JCT Design and Build Contract 2011. FIDIC 1999 contracts also contain a similar provision in the event of delay for 'exceptionally adverse climatic conditions' (eg clause 8.4(c) in the Red Book). There is, however, no definition in either of these as to what will constitute exceptionally adverse weather—so what sort of weather conditions would qualify?
There is no easy answer as to what constitutes exceptionally adverse weather. In some circumstances it may be obvious, for example, a contractor whose works are delayed because the site of the works is affected by extreme flooding, such as those which have featured in the news in the UK in the last few years, would be likely to be entitled to an extension of time due to exceptionally adverse rainfall having prevented the works being completed on
Free trials are only available to individuals based in the UK
Complete all the fields above to proceed to the next step.
**Trials are provided to all LexisPSL and LexisLibrary content, excluding Practice Compliance, Practice Management and Risk and Compliance, subscription packages are tailored to your specific needs. To discuss trialling these LexisPSL services please email customer service via our online form. Free trials are only available to individuals based in the UK. We may terminate this trial at any time or decide not to give a trial, for any reason. Trial includes one question to LexisAsk during the length of the trial.
To view the latest version of this document and thousands of others like it, sign-in to LexisPSL or register for a free trial.
Existing user? Sign-in
Take a free trial
Take a free trial
Property: [insert name and/or address of the Property] (‘Property’)Purchaser: [insert name, address and (if applicable) company registration number of buyer]Transaction: [insert brief details]1Executive summary1.1Scope of reportThis report is addressed to you [insert buyer’s name] and has been
Multilateral Trading Facilities (MTFs)BREXIT: 11pm (GMT) on 31 December 2020 (‘IP completion day’) marked the end of the Brexit transition/implementation period entered into following the UK’s withdrawal from the EU. Following IP completion day, key transitional arrangements come to an end and
Skeleton argumentsThis Practice Note provides guidance on the interpretation and application of the relevant provisions of the CPR. Depending on the court in which your matter is proceeding, you may also need to be mindful of additional provisions—see further below.Note: this Practice Note does not
The third edition of the Standard Commercial Property Conditions was published on 27 April 2017 a
0330 161 1234